建设工程监理合同，监理合同版本

2000版建设工程委托监理合同

(中英文)

CONTRACT FOR ENTRUSTED SUPERVISION

OF CONSTRUCTION PROJECT



中英文1.2万余字，word 文档。

学术交流请私信或评论留言



目录 TABLE OF CONTENTS

第一部分　建设工程委托监理合同

Part I Contract for entrusted supervision of construction project

第二部分 标准条件

PART II STANDARD CONDITIONS

词语定义、适用范围和法规 Definition of words, scope of application and law / regulations

监理人的义务

OBLIGATIONS OF THE SUPERVISOR

委托人的义务

OBLIGATIONS OF THE CLIENT

监理人的权利

Rights of the Supervisor

委托人的权利 Rights of the Client

监理人的责任

Liabilities of the Supervisor

委托人的责任 Liabilities of Client

本合同生效、变更与终止

Effectiveness, Alternation and Termination of Contract

监理报酬 Payment for Supervision

其他 Miscellaneous

争议的解决Settlement of Disputers

第三部分 专用条件

Part III particular conditions



部分章节示例如下：

监理人的义务

OBLIGATIONS OF THE SUPERVISOR

第四条 监理人应派出监理工作需要的监理机构及监理人员，向委托人报送委派的总监理工程师及其监理机构主要成员名单，监理规划，完成监理合同专用条件中约定的监理工程范围内的监理业务。在履行本合同义务期间，应按合同约定定期向委托人报告监理工作。

Article 4 The Supervisor shall designate the Supervision Team and Supervisory personnel necessary for carrying out the supervising works; submits to the Client a name-list of the Chief Supervision Engineer, main staff of the Supervision Team and a supervision schedule and complete the supervision business within the scope of the supervision project as stipulated in the particular conditions of the supervision contract.The Supervisor shall, during the execution of the Contract, submit supervision report to the Client at regular interval as stated in the Contract.



第五条 监理人应认真，勤奋地工作，在履行合同义务时为委托人提供与其水平相应的

咨询意见，公正维护各方的合法权益。

Article 5 The Supervisor shall exercise reasonable care and diligence, provide consult opinion to the Client with an appropriate level in the performance of the obligations under the Contract and safeguard the legitimate rights and interests of all parties.



第六条 监理人使用委托人提供的设施和物品属委托人的财产，应恰当使用和维护。在监理工作完成或中止时，应将其设施和剩余的物品完好地移交给委托人。

Article 6 Any facilities and articles supplied by the Client for use by the Supervisor shall be properly used and maintained and remain the property to the Client . When the services are completed or terminated the Supervisor shall deliver to the Client such facilities and unconsumed articles in good working order.



第七条 合同期内或本合同终止后，未征得委托人同意，不得泄露与本工程和本 合同有关的保密信息。

Article 7 During the contract period or after the Contract is terminated, without the consent of the Client, the Supervisor shall not disclose the confidential information in relation to the Project and the Contract.

委托人的义务OBLIGATIONS OF THE CLIENT

第八条 委托人在监理人开展监理业务之前应向监理人支付预付款。

Article 8 The Client shall pay an advance payment to the Supervisor prior to the commencement of the services of the Supervisor.



第九条 委托人应当负责工程建设的所有外部关系的协调，为监理工作提供外部条件。根据需要，如将部分或全部协调工作委托监理人承担，则应在专用条件中明确委托的工作和相应的报酬。

Article 9 The client shall be responsible for all coordination of external relationships in relation to the construction of the project. If the client entrusts part or all of such coordination works to the supervisor as is necessary, then the work to be entrusted and relevant terms of remuneration shall be specified in the supplemental clauses.



第十条 委托人应当在双方约定的时间内免费向监理人提供与工程有关的为监理工作所需要的工程资料。

Article 10 The client shall, within the agreed time, provide the supervisor, free of charge, with engineering information pertaining to the project and necessary for the supervision services.



第十一条 委托人应当在专用条件约定的时间内就监理人向委托人以恰当的书面形式提交的一切事宜作出书面决定。

Article 11 The client shall, within the time specified in the conditions of Particular condition hereof, give his decision in writing on all issues which properly referred in writing by the supervisor.



第十二条 委托人应当授权一名熟悉工程情况、能在规定时间内作出决定的常驻代表（在专用条款中约定），负责与监理人联系。更换常驻代表，要提前通知监理人。

Article 12 The client shall appoint a its representative (to be specified in the conditions of particular condition) which is familiar with the project and able to make decision within specified time for the purpose of contacting the supervisor. Should the client's representative be replaced, the client shall notify the supervisor in advance.



第十三条 委托人应当将授予监理人的监理权利，以及监理人主要成员的职能分工、监理权限及时书面通知已选定的承包合同的承包人，并在与第三人签订的合同中予以明确。

Article 13 The client shall timely notify the awarded contractor, in writing, of the power of the supervisor, roles and authorities of main staff of the supervisor and shall explicitly state thereof in the contract signed by the client and any third party.



第十四条 委托人应在不影响监理人开展监理工作的时间内提供如下资料：

Article 14 The Client shall provide Contractor with the following information within the time that the supervisor is not affected to carry out the supervision work.



(1) List of suppliers & manufacturers, in cooperation with the project, of the raw materials, components and parts, mechanical equipment etc. to be used in the Project;

与本工程合作的原材料、构配件、机械设备等生产厂家名录。



(2) 提供与本工程有关的协作单位、配合单位的名录。

Provide the list of the cooperation units and coordinating units which in relation to the project.



第十五条 委托人应免费向监理人提供办公用房、通讯设施、监理人员工地住房及合同专用条件约定的设施，对监理人自备的设施给予合理的经济补偿（补偿金额=设施在工程使用时间占折旧年限的比例×设施原值十管理费）。

Article 15 The client shall provide, free of charge, the supervisor with office space, communication facilities, supervision personnel's site housing and facilities which stipulated in the particular conditions hereof, and give reasonable economic compensation to the facilities owned by the supervisor (compensation amount = the proportion of the facilities in the project service time to the depreciation period × facility original value 十 administrative fees).



第十六条 根据情况需要，如果双方约定，由委托人免费向监理人提供其他人员，应在监理合同专用条件中予以明确。

Article 16 The client shall, as the case may require and the parties’ agreement, provide other personnel, free of charge, which should be explicitly stated in the particular condition.



监理人的权利Rights of the Supervisor

第十七条 监理人在委托人委托的工程范围内，享有以下权利：

Article 17 The Supervisor should have the following rights within his scope of work.

(1) 选择工程总承包人的建议权；

The right to select the recommendations of the general contractor.



(2) The right to select the recommendations of the subcontractor;

选择工程分包人的建议权和义务；



(3) 对工程建设有关事项包括工程规模、设计标准、规划设计、生产工艺设计和使用功能要求，向委托人的建议权。

The right to make recommendations to the Client in the respects of the project including project size, design standard, planning design, technological design and performance requirements.



(4) 对工程设计中的技术问题，按照安全和优化的原则，向设计人提出建议；如果拟提出的建议可能会提高工程造价，或延长工期，应当事先征得委托人的同意。当发现工程设计不符合国家颁布的建设工程质量标准或设计合同约定的质量标准时，监理人应当书面报告委托人并要求设计人更正。

To put forward suggestions to designers for technical problems in engineering design according to the principles of safety and optimization; if the proposal may increase the project cost or extend the construction period, the consent of the client shall be obtained in advance. Where it is found that the engineering design does not conform to the construction engineering quality standards promulgated by the State or the quality standards stipulated in the design contract, the supervisor shall report to the client in writing and require the designer to correct it.



(5) 审批工程施工组织设计和技术方案，按照保质量、保工期和降低成本的原则，向承包人提出建议，并向委托人提出书面报告。

Respect to examination and approval of design and technical scheme made by the project construction organization, pursuant to the principles of quality warranty, time limit and cost reduction, make recommendations to the contractor and submit a written report to the client.

(6) 主持工程建设有关协作单位的组织协调，重要协调事项应当事先向委托人报告。

Responsible for the organization and coordination of the cooperative units involved in the construction of the project, and important coordination matters shall be reported to the client in advance



(7) 征得委托人同意，监理人有权发布开工令、停工令、复工令，但应当事先向委托人报告。如在紧急情况下未能事先报告时，则应在24小时内向委托人作出书面报告。

With the consent of the client, the supervisor shall have the right to issue orders of commencement, shutdown and a resumption, however, shall report to the client in advance. If failure to report in advance in case of emergency, a written report shall be made to the client within 24 hours.



(8) 工程上使用的材料和施工质量的检验权。对于不符合设计要求和合同约定及国家质量标准的材料、构配件、设备，有权通知承包人停止使用；对于不符合规范和质量标准的工序、分部分项工程和不安全施工作业，有权通知承包人停工整改、返工。承包人得到监理机构复工令后才能复工。

The right to inspect the materials used in the project and the construction quality. For the materials, components, fittings and equipment which do not meet the design requirements, contract stipulations and State’s quality standards, they have the right to notify the contractor to stop using them; For the processes, partial projects and unsafe construction operations which do not meet the specifications and quality standards, the contractor shall have the right to be notified to stop work for rectification and rework. The contractor cannot resume work until he receives the supervision organization's order to resume work.

(9) 工程施工进度的检查、监督权，以及工程实际竣工日期提前或超过工程施工合同规定的竣工期限的签认权。

Rights to check, supervise the progress of the construction and right to ratify that the actual completion is ahead or behind the completion date specified in the construction contract.



(10) 在工程施工合同约定的工程价格范围内，工程款支付的审核和签认权，以及工程结算的复核确认权与否决权。未经总监理工程师签字确认，委托人不支付工程款。

Right check and certify by signature that the payment to the construction contractor within the scope of the construction contract, and recheck, confirm, and negate to the settlement of the accounts. Without the signature and confirmation from the chief supervision engineer, the client will not make payment to the construction contractor.

第十八条 监理人在委托人授权下，可对任何承包人合同规定的义务提出变更。如果由此严重影响了工程费用或质量、或进度，则这种变更须经委托人事先批准。在紧急情况下未能事先报委托人批准时，监理人所做的变更也应尽快通知委托人。在监理过程中如发现工程承包人人员工作不力，监理机构可要求承包人调换有关人员。

The supervisor may, under the authorization of the client, propose amendment or changes to any contractor's obligations hereunder. If the project cost or quality or progress is seriously affected, such amendment or change shall be subject to the prior approval of the client. In case of failure to report to the client for approval in advance in emergency, the supervisor shall notify the client of the same as soon as practicable. In the process of supervision, if it is found that the project contractor's personnel are ineffective, the supervision organization may require the contractor to replace the relevant personnel.



第十九条　在委托的工程范围内，委托人或承包人对对方的任何意见和要求（包括索赔要求），均必须首先向监理机构提出，由监理机构研究处置意见，再同双方协商确定。当委托人和承包人发生争议时，监理机构应根据自己的职能，以独立的身份判断，公正地进行调解。当双方的争议由政府建设行政主管部门调解或仲裁机关仲裁时，应当提供作证的事实材料。



委托人的权利Rights of the Client

第二十条　委托人有选定工程总承包人，以及与其订立合同的权利。

Article 20 The client has the right to select the general contractor and enter into a contract therewith.



第二十一条 委托人有对工程规模、设计标准、规划设计、生产工艺设计和设计使用功能要求的认定权，以及对工程设计变更的审批权。

Article 21 The Client’s the right to decide the project size and agree the design standard, planning design, technological design and designed performance requirements and the right to approve construction amendment.



第二十二条 监理人调换总监理工程师须事先经委托人同意。

Article 22 The replacement of the chief supervisioin engineer by the supervisor should be subject to prior consent of the client.



第二十三条 委托人有权要求监理人提交监理工作月报及监理业务范围内的专项报告。

Article 23 The Client has the right to require the Supervisor to submit supervision onthly report and specific report within the Supervisor’s scope of work..



第二十四条 当委托人发现监理人员不按监理合同履行监理职责，或与承包人串通给委托人或工程造成损失的，委托人有权要求监理人更换监理人员，直到终止合同并要求监理人承担相应的赔偿责任或连带赔偿责任。

Article 24 In the event that the client find the supervisor’s staff fails to perform duties under the contract, or cause any loss to the project, the client shall be entitled to require that such staff be replaced by the supervisor or even terminate the contract and demand the supervisor to assume responsibilities or contiguous responsibilities in paying compensation.



监理人的责任Liabilities of the Supervisor

第二十五条 监理人的责任期即委托监理合同有效期。在监理过程中，如果因工程建设进度的推迟或延误而超过书面约定的日期，双方应进一步约定相应延长的合同期。

Article 25 The Supervisor’s liability period is the valid period of the Contract. In the event extenssion of the liability period due to the postponement or delay or he project programme, the parties shall make further negotiation to agree an extension of the Contract Period.



第二十六条　监理人在责任期内，应当履行约定的义务，如果因监理人过失而造成了委托人的经济损失，应当向委托人赔偿。累计赔偿总额（除本合同第二十四条规定以外）不应超过监理报酬总额（除去税金）。

Article 26 The Supervisor shall, during the Contract Period, perform his duties. Should any financial loss be caused by the fault of the Supervisor, the Supervisor shall pay compensation to the Client. Accumulated amount of compensation (except for the compensation specified in Article 24) shall not exceed the total payment by the Client to the Supervisor (excluding income tax).



第二十七条　监理人对承包人违反合同规定的质量要求和完工（交图、交货）时限，不承担责任。因不可抗力导致委托监理合同不能全部或部分履行，监理人不承担责任。但对违反第五条规定引起的与之有关的事宜，向委托人承担赔偿责任。

Article 27 The supervisor shall be not responsible for any contractor’s nonconformity in quality requirements and completion time (for submission of drawings or delivery of goods). In the event of any force majeure which cause part or all of the execution of the contract to be impossible, the supervisor shall not be held responsible, however, for any infringement to article 5, the supervisor shall pay compensation to the client.



第二十八条　监理人向委托人提出赔偿要求不能成立时，监理人应当补偿由于该索赔所导致委托人的各种费用支出。

Article 28 If the claim made by the supervisor to the client cannot be satisfied, the supervisor shall be responsible for any cost incurred by the client in relation to the claim.

委托人的责任Liabilities of Client

第二十九条　委托人应当履行委托监理合同约定的义务，如有违反则应当承担违约责任，赔偿给监理人造成的经济损失。

监理人处理委托业务时，因非监理人原因的事由受到损失的，可以向委托人要求补偿损失。

Article 29 The client shall carry out his duties as stated in the contract and shall be liable to the supervisor if a breach of his duty and shall pay compensation for the supervisor’s direct financial loss.

The supervisor may, where dealing with entrusted business, claim compensation from the client for loss due to the cause of non-supervisor.



第三十条　委托人如果向监理人提出赔偿的要求不能成立，则应当补偿由该索赔所引起的监理人的各种费用支出。

Article 30 Provided that the claim made by the client to the supervisor cannot be satisfied, the client shall be responsible for any cost incurred by the supervisor in relation to the claim.